Terms of Service
1. Overview
Welcome to Michigan Solutions.
These Terms of Service (“Terms”) govern your access to and use of our products, services, website, and related communications. By requesting a quotation, purchasing products, submitting inquiries, or otherwise engaging with Michigan Solutions, you acknowledge that you have read, understood, and agree to be bound by these Terms.
Michigan Solutions provides engineered geosynthetic solutions and related products designed to support infrastructure, construction, environmental, and civil engineering projects throughout the Philippines.
2. Products and Services
Michigan Solutions supplies engineered geosynthetic products and provides related technical support, consultation, and project assistance.
All product descriptions, specifications, technical data sheets, illustrations, and marketing materials are provided for general informational purposes only. Product availability, specifications, and pricing may change without prior notice as part of our commitment to continuous product improvement.
Recommendations provided by Michigan Solutions are based on the information supplied by the customer and should not replace project-specific engineering analysis or professional design.
3. Quotations and Orders
All quotations issued by Michigan Solutions are subject to availability, pricing adjustments, and final confirmation.
Submission of a quotation request does not constitute acceptance of an order. Orders become effective only after written confirmation from Michigan Solutions.
Michigan Solutions reserves the right to refuse, modify, or cancel any quotation or order due to product availability, pricing errors, force majeure events, regulatory requirements, or other legitimate business reasons.
4. Pricing and Payment
Unless otherwise stated in writing:
- Prices are subject to change without prior notice.
- Applicable taxes, freight, delivery charges, and other government-imposed fees may be charged separately.
- Payment terms shall be those indicated in the approved quotation, invoice, purchase agreement, or other written contract between Michigan Solutions and the customer.
- Failure to comply with payment terms may result in delays, suspension of deliveries, or cancellation of pending orders.
5. Delivery
Michigan Solutions will make reasonable efforts to deliver products within the agreed schedule.
Delivery dates are estimates and may be affected by manufacturing schedules, logistics, supplier delays, customs processing, weather conditions, force majeure events, or circumstances beyond our reasonable control.
Michigan Solutions shall not be liable for delays resulting from these events.
6. Customer Responsibilities
Customers are responsible for:
- Providing complete and accurate project information.
- Reviewing product specifications before purchase.
- Ensuring that selected products are appropriate for the intended application.
- Following applicable installation procedures, engineering standards, and safety requirements.
Where necessary, customers should consult licensed engineers or qualified project professionals before installation or implementation.
7. Technical Information
Michigan Solutions may provide technical guidance, design assistance, or product recommendations.
Such assistance is intended to support customers during product selection and project planning and should not be interpreted as a substitute for independent engineering judgment, project design, or regulatory approval.
Final responsibility for project design, structural integrity, installation methods, and regulatory compliance remains with the customer, project owner, engineer of record, or contractor.
8. Warranty Disclaimer
Michigan Solutions endeavors to supply products that meet applicable quality standards.
Except where expressly provided in a written warranty or contract, products and services are provided “as is” and “as available.” Michigan Solutions disclaims all implied warranties, including warranties of merchantability and fitness for a particular purpose, to the extent permitted by applicable law.
9. Limitation of Liability
To the fullest extent permitted by law, Michigan Solutions shall not be liable for any indirect, incidental, consequential, special, exemplary, or punitive damages arising from the use of its products, services, website, or technical information.
Michigan Solutions’ total liability, if any, shall not exceed the purchase price paid for the specific product or service giving rise to the claim, unless otherwise required by applicable law or agreed upon in writing.
10. Intellectual Property
All website content, product documentation, technical drawings, specifications, trademarks, logos, graphics, photographs, and other intellectual property remain the exclusive property of Michigan Solutions or its licensors.
No material may be copied, reproduced, modified, distributed, or used for commercial purposes without prior written permission.
11. Privacy
Michigan Solutions collects and processes personal information in accordance with its Privacy Policy.
By using our services or submitting information through our website, you consent to the collection and processing of your information as described in the Privacy Policy.
12. Force Majeure
Michigan Solutions shall not be responsible for delays or failure to perform obligations resulting from events beyond its reasonable control, including but not limited to natural disasters, acts of government, labor disputes, transportation disruptions, pandemics, power outages, supplier shortages, cyber incidents, or other force majeure events.
13. Changes to These Terms
Michigan Solutions reserves the right to modify these Terms of Service at any time.
Updated versions will become effective immediately upon publication on our website unless otherwise specified. Continued use of our website, products, or services constitutes acceptance of the revised Terms.
14. Governing Law
These Terms shall be governed by and interpreted in accordance with the laws of the Republic of the Philippines.
Any dispute arising from these Terms or the use of Michigan Solutions’ products or services shall be subject to the exclusive jurisdiction of the appropriate courts in the Philippines.
15. Contact Information
For questions regarding these Terms of Service, our products, or our services, please contact Michigan Solutions using the contact information provided on our website.